Code of Federal Regulations · Section
§ 42.1302 — 42.1302 Suspension Of Work
48 C.F.R. § 42.1302
View:
A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.
Authorizing Statute
-
Administrative40 U.S.C. § 121
-
Chapter 137 legacy provisions10 U.S.C. § 3016
-
General authority41 U.S.C. § 1121
-
Powers of the Administration in performance of functions51 U.S.C. § 20113