§ 3452.242-71 — 3452.242-71 Notice To The Government Of Delays

As prescribed in 3442.7002, insert the following clause in all solicitations and contracts other than purchase orders:

The contractor shall notify the contracting officer of any actual or potential situation, including but not limited to labor disputes, that delays or threatens to delay the timely performance of work under this contract. The contractor shall immediately give written notice thereof, including all relevant information.