§ 832.111-70 — 832.111-70 Va Contract Clauses For Non-commercial Purchases

(a) (1) Insert the clause at 852.232-70, Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract does not require use of the “Network Analysis System—Critical Path Method (NAS-CPM).”

(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.

(b) (1) Insert the clause at 852.232-71, Payments Under Fixed-Price Construction Contracts (Including NAS-CPM), in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract requires use of the “Network Analysis System—Critical Path Method (NAS-CPM).”

(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.